№ files_lp_4_process_3_057840
File format: docx
Character count: 4171
File size: 29 KB
Guidelines and contract specifications for determining project completion dates, associated liquidated damages, and restrictions on tree removal as part of construction contracts.
Year:
2021
Region / City:
Not specified
Document Type:
Construction contract clause
Subject:
Completion dates and assessment of liquidated damages
Organization / Agency:
Department of Transportation (implied)
Audience:
Contractors and project managers
Options for Completion Date:
Option 1, Option 2, Option 3
Liquidated Damages Rate:
$1,000 per hour or per day depending on option
Milestone Requirements:
Specified per project team verification
Tree Removal Restrictions:
May 15 – July 31, $477 per affected tree
Contractual References:
Section 108.07.03, Section 108.09
Completion Period Limitations:
Calendar/working days, seasonal/weather considerations
Notification Requirements:
Contractor must notify department of start date at least two weeks prior
Price: 8 / 10 USD
The file will be delivered to the email address provided at checkout within 12 hours.
The file will be delivered to the email address provided at checkout within 12 hours.
Don’t have cryptocurrency yet?
You can still complete your purchase in a few minutes:- Buy Crypto in a trusted app (Coinbase, Kraken, Cash App or any similar service).
- In the app, tap Send.
- Select network, paste our wallet address.
- Send the exact amount shown above.
The final amount may vary slightly depending on the payment method.
The file will be sent to the email address provided at checkout within 24 hours.
The product description is provided for reference. Actual content and formatting may differ slightly.
Type of document:
Contract supplement / construction contract conditions
Related document:
General Conditions
Subject:
Liquidated damages for delay in completion
Contracting authority:
Group Director (OGS D&C Contract Management)
Monetary penalty:
$1,000.00 per day for substantial completion delay; $500.00 per day for physical completion delay
Approval requirement:
Written approval required from Business Unit Leader and Contracting Officer for edits
Applicable section references:
Article 2, Article 13, Section 2.21, Section 2.12, Article 21, Section 011000
Jurisdiction/organization:
State (New York State OGS implied)
Language:
English
Year:
2025-2026
Region / City:
Florida
Subject:
Liquidated damages, construction contract
Document type:
Contract amendment
Organization / Institution:
Florida Department of Transportation
Author:
Unknown
Target audience:
Contractors
Effective period:
From the date of contract signing
Approval date:
2023-09-21
Amendment date:
2023-05-24
Context:
A contract amendment outlining liquidated damages for failure to complete construction work on time, including specific daily charges based on the contract amount.
Year:
2026
Region / City:
Baton Rouge, LA
Topic:
Liquidated Damages Calculation
Document Type:
Procedure / Form
Author:
Facility Planning & Control
Target Audience:
Contractors, Project Managers
Period of Effectiveness:
N/A
Approval Date:
N/A
Amendment Date:
N/A
Type of document:
Contract supplement / construction contract conditions
Related document:
General Conditions
Subject:
Liquidated damages for delay in completion
Contracting authority:
Group Director (OGS D&C Contract Management)
Monetary penalty:
$1,000.00 per day for substantial completion delay; $500.00 per day for physical completion delay
Approval requirement:
Written approval required from Business Unit Leader and Contracting Officer for edits
Applicable section references:
Article 2, Article 13, Section 2.21, Section 2.12, Article 21, Section 011000
Jurisdiction/organization:
State (New York State OGS implied)
Language:
English
Court:
Court of Common Pleas, Cuyahoga County, Ohio
Case Number:
CV 16 867545
Judge:
William J. Coyne
Plaintiff:
Estate of Leona Maxim by Christine Guest, Executor
Defendants:
Kindred Nursing & Rehab – Stratford, et al.; KND Development 51, LLC d/b/s Kindred Transitional Care and Rehabilitation—Stratford
Document Type:
Jury instructions, interrogatories, and verdict form
Subject Matter:
Punitive damages; employer liability; alteration or falsification of medical records; attorney fees
Related Authority:
OJI-CV 537.07; OJI-CV 303.07; OJI-CV 315.37(11); Moskovitz v. Mt. Sinai Med. Ctr., 69 Ohio St.3d 638 (1994)
Date:
October 2016
Jurisdiction:
Cuyahoga County, Ohio
Note:
Year
Jurisdiction:
Supreme Court of Western Australia
Document number:
Form 35
Legislation referenced:
Rules of the Supreme Court 1971 Order 13 r. 3, 4, 14; Order 42 r. 1; Civil Judgments Enforcement Act 2004 s. 15
Subject matter:
Default judgment; assessment of damages; costs; enforcement of judgment
Type of document:
Court order form and notice to defendant
Issuing body:
Supreme Court of Western Australia
Addressee:
Defendant in civil proceedings
Related officer:
Registrar; Judicial officer; Taxing Officer
Date of insertion:
16 November 2016 (Gazette p. 52078)
Procedural context:
Entry of default judgment following certification of assessed damages and taxation of costs
Number:
24.09H
Title:
Breach of Contract—Reliance Damages
Jurisdiction:
United States
Area of Law:
Contract Law
Subject:
Reliance Damages in Breach of Contract Actions
Type of Document:
Jury Instruction
Related Provisions:
Instruction 24.11 (Nominal Damages); Instruction 24.09A
Legal Sources Cited:
Restatement (Second) of Contracts § 349; Restatement (Second) of Contracts § 344
Purpose:
Guidance to jury on awarding compensatory and nominal damages based on reliance interest
Applicable Context:
Civil action for breach of contract
Measure of Damages:
Expenditures made in preparation for or in performance of the contract, subject to reduction for proven loss
Year:
[Not specified]
Region / City:
Sacramento, California
Subject:
Legal action, injunction
Document type:
Complaint
Organization / Institution:
Superior Court of California
Author:
Plaintiff (Your Name)
Target Audience:
Legal professionals, parties involved in the case
Effective period:
[Not specified]
Approval date:
[Not specified]
Date of amendments:
[Not specified]
Year:
2025-2026
Region / City:
Florida
Subject:
Liquidated damages, construction contract
Document type:
Contract amendment
Organization / Institution:
Florida Department of Transportation
Author:
Unknown
Target audience:
Contractors
Effective period:
From the date of contract signing
Approval date:
2023-09-21
Amendment date:
2023-05-24
Context:
A contract amendment outlining liquidated damages for failure to complete construction work on time, including specific daily charges based on the contract amount.
Year:
2026
Region / City:
Baton Rouge, LA
Topic:
Liquidated Damages Calculation
Document Type:
Procedure / Form
Author:
Facility Planning & Control
Target Audience:
Contractors, Project Managers
Period of Effectiveness:
N/A
Approval Date:
N/A
Amendment Date:
N/A
Year:
2001
Region / City:
Colorado
Topic:
Damages and Legal Instructions
Document Type:
Legal Instruction
Agency / Institution:
Court of Appeals, Colorado
Author:
Not specified
Target Audience:
Legal professionals, juries
Period of Validity:
Not specified
Approval Date:
Not specified
Amendment Date:
Not specified
Note:
Contextual Description
Note:
Year
Year:
2023
Region / City:
United States
Topic:
Legal instructions, personal injuries, damages
Document Type:
Legal guideline
Author:
Unknown
Target Audience:
Legal professionals, judges, and lawyers
Period of Validity:
Ongoing
Approval Date:
Not specified
Date of Changes:
Not specified
Year:
1985
Region / City:
Florida
Topic:
Legal/Compensation
Document Type:
Legal Text
Organ / Institution:
Florida Statutes
Author:
Florida Legislative Committee
Target Audience:
Legal Professionals
Period of Effect:
Ongoing
Date of Approval:
1985
Date of Changes:
None
Year:
1989
Jurisdiction:
Wisconsin, USA
Subject:
Misrepresentation, Liability, Damages
Document Type:
Legal memorandum / law note
Institution:
Wisconsin Supreme Court, Wisconsin Judicial System
Audience:
Trial judges, legal practitioners
Legal References:
Economic Loss Doctrine, Wis. Stat. § 100.18, Wis. Stat. § 895.446
Misrepresentation Types:
Intentional, Strict Responsibility, Negligent
Damages Measurement:
Benefit-of-the-bargain, Out-of-pocket rule
Applications:
Property transactions, Residential and commercial real estate
Exceptions:
Personal injury, damage to other property, fraud in inducement
Year:
2001
Region / City:
Colorado
Subject:
Civil law, damages, legal defense
Document Type:
Legal instruction
Organization / Institution:
Colorado Court of Appeals
Author:
Colorado Court of Appeals
Target Audience:
Legal professionals, judges, and jurors
Effective Period:
2001
Approval Date:
2001
Amendment Date:
N/A
Context:
A legal source outlining instructions for determining damages and affirmative defenses in civil cases, including failure to mitigate and nonuse of safety belts.
Date:
April 18, 2025
Document type:
Public notice
Environmental review framework:
City Environmental Quality Review (CEQR) and State Environmental Quality Review Act (SEQRA)
SEQRA classification:
Type I
Project name:
Long Island City Neighborhood Plan
CEQR number:
25DCP001Q
ULURP numbers:
250175HAQ; 250176ZMQ; N250177ZRQ; 250178PCQ; 250179PPQ; 250180PPQ
Lead agency:
City Planning Commission
Proposing agency:
New York City Department of City Planning
Contact person:
Stephanie Shellooe, AICP, Director
Responsible division:
Environmental Assessment and Review Division
Project location:
Long Island City, Queens, New York
Community districts:
Queens Community District 2; Queens Community District 1
Project area size:
Approximately 54 blocks
Primary subject:
Land use actions and zoning changes
Actions covered:
Zoning map amendments, zoning text amendments, special district modifications, urban development action area designation, city map changes, disposition and acquisition of city-owned property
Public participation:
Public hearing and written comment period following hearing
Availability:
Public inspection and online access via ZAP project page
Year:
Not specified
Region / City:
Not specified
Subject:
Biological risk assessment, genetic modification, COSHH
Document type:
Guidance document
Organization:
Genetic Modification Safety Management Committee (GMSMC)
Author:
Not specified
Target audience:
Employees, Users, Tenants, visitors, Principal Investigators
Period of validity:
Not specified
Approval date:
Not specified
Amendment date:
Not specified